Among trade contractors, meeting the labor budget is at best a strain. Some surveys show that but for change orders and buy-outs, the craft contractor would be hard pressed to make profit on its jobs. With a ripple of a trend of owners pre-purchasing equipment and material, leaving the contractor to be only a labor contractor, the challenge of managing field labor intensifies. Documentation, believe it or not, is one of the tools for enhancing the probability of making one's labor budget. This webinar is a brief overview of the role of documentation in labor (and therefore profit) management.
2. 2
The Role of the Project Team
1. Meet or Beat Budget
2. Comply with Contract
3. Protect contract from encroachment by others
4. Be contractor of choice in the future
The Performance on this project governs future
opportunities
5. Continue to get better
Those who don’t will be called “ex‐contractors”.
Those who do have another 40 years ahead of
them.
6. Do things you don’t like to do!
15. 15
Labor Risk – Within Your Control
Planning Meetings::
InternalInternal – maintain minutes! You have a duty to plan and
coordinate, to exercise control over your own production
flow.
How to Avoid Waste Focus Meetings:Focus Meetings:
With key personnel to figure out how to improve, how to
work around problems. Also becomes important in pre‐
qualification proposals.
Project Planning Meetings:Project Planning Meetings:
Input should include “subject to work area being available”;
“subject to receipt of answer RFI# ___ by _________”, etc.
Warning:Warning:
If you provide dates, durations and miss your own dates, miss your own dates, you
have set up your report card to get failing grades.failing grades.
30. 30
If the Contracting Officer does not respond to my request, I can do one of
several things:
Notify him that as he has not responded, that I will accelerate in
attempting to meet the original contract schedule or
Because of impossibility of meeting the original contract schedule due to
the acts/omissions of the government as set forth in my request for a
time extension, this is notification that I am entitled to the additional
time and I consider the contract schedule has been constructively
extended and that I will submit cost for the delay at a later time. Also, I
will ask for a status of the condition of the government funding to assure
that I can get paid if I incur additional cost as result of the delay.
If the government does nothing and does not send me letters telling me I
am behind and does not threaten liquidated damages, I can hopefully
rely on my lawyer to use the doctrine of waiver which would at least let
me off the hook for default termination and liquidated damages. But I
don’t want to rely on waiver.
I want to emphasize the importance of notice, effectively updating the
schedule and showing the impact to the critical path, and having daily
reports which are consistent with the causes of the delay and the delay
itself.
33. 33
How to Handle – What If’s
The General Contractor does not update the project schedule
effectively (It is just a billing schedule and not really used to manage
the project).
The General Contractor states to you that, “There are plenty of places
for you to work so you are not being damaged because the perimeter
walls have not been installed.”
The General Contractor states: “The critical path has not been
extended so you are not entitled to a claim for delay.”
The General Contractor states: “You didn’t meet your own dates.” or
“You haven’t manned up to the job as you should have.”
The General Contractor says: “Well you have been on the job a year
now and never complained about the schedule before.”